VA 01 32 16 15-2010 PROJECT SCHEDULES (SMALL PROJECTS DESIGN BID BUILD).pdf

《VA 01 32 16 15-2010 PROJECT SCHEDULES (SMALL PROJECTS DESIGN BID BUILD).pdf》由会员分享，可在线阅读，更多相关《VA 01 32 16 15-2010 PROJECT SCHEDULES (SMALL PROJECTS DESIGN BID BUILD).pdf（10页珍藏版）》请在麦多课文档分享上搜索。

1、04-10M 01 32 16.15 - 1 SECTION 01 32 16.15 PROJECT SCHEDULES (SMALL PROJECTS DESIGN/BID/BUILD) PART 1- GENERAL 1.1 DESCRIPTION: A. The Contractor shall develop a Critical Path Method (CPM) plan and schedule demonstrating fulfillment of the contract requirements (Project Schedule), and shall keep the

2、 Project Schedule up-to-date in accordance with the requirements of this section and shall utilize the plan for scheduling, coordinating and monitoring work under this contract (including all activities of subcontractors, equipment vendors and suppliers). Conventional Critical Path Method (CPM) tech

3、nique shall be utilized to satisfy both time and cost applications. 1.2 CONTRACTORS REPRESENTATIVE: A. The Contractor shall designate an authorized representative responsible for the Project Schedule including preparation, review and progress reporting with and to the Contracting Officers Representa

4、tive (COTR). B. The Contractors representative shall have direct project control and complete authority to act on behalf of the Contractor in fulfilling the requirements of this specification section. C. The Contractors representative shall have the option of developing the project schedule within t

5、heir organization or to engage the services of an outside consultant. If an outside scheduling consultant is utilized, Section 1.3 of this specification will apply. 1.3 CONTRACTORS CONSULTANT: A. The Contractor shall submit a qualification proposal to the COTR, within 10 days of bid acceptance. The

6、qualification proposal shall include: 1. The name and address of the proposed consultant. 2. Information to show that the proposed consultant has the qualifications to meet the requirements specified in the preceding paragraph. 3. A representative sample of prior construction projects, which the pro

7、posed consultant has performed complete project scheduling services. These representative samples shall be of similar size and scope. B. The Contracting Officer has the right to approve or disapprove the proposed consultant, and will notify the Contractor of the VA decision within seven calendar day

8、s from receipt of the qualification proposal. In case of disapproval, the Contractor shall resubmit another consultant within 10 calendar days for renewed consideration. The Contractor shall Provided by IHSNot for ResaleNo reproduction or networking permitted without license from IHS-,-,-04-10M 01 3

9、2 16.15 - 2 have their scheduling consultant approved prior to submitting any schedule for approval. 1.4 COMPUTER PRODUCED SCHEDULES A. The contractor shall provide monthly, to the Department of Veterans Affairs (VA), all computer-produced time/cost schedules and reports generated from monthly proje

10、ct updates. This monthly computer service will include: three copies of up to five different reports (inclusive of all pages) available within the user defined reports of the scheduling software approved by the Contracting Officer; a hard copy listing of all project schedule changes, and associated

11、data, made at the update and an electronic file of this data; and the resulting monthly updated schedule in PDM format. These must be submitted with and substantively support the contractors monthly payment request and the signed look ahead report. The COTR shall identify the five different report f

12、ormats that the contractor shall provide. B. The contractor shall be responsible for the correctness and timeliness of the computer-produced reports. The Contractor shall also responsible for the accurate and timely submittal of the updated project schedule and all CPM data necessary to produce the

13、computer reports and payment request that is specified. C. The VA will report errors in computer-produced reports to the Contractors representative within ten calendar days from receipt of reports. The Contractor shall reprocess the computer-produced reports and associated diskette(s), when requeste

14、d by the Contracting Officers representative, to correct errors which affect the payment and schedule for the project. 1.5 THE COMPLETE PROJECT SCHEDULE SUBMITTAL A. Within 45 calendar days after receipt of Notice to Proceed, the Contractor shall submit for the Contracting Officers review; three blu

15、e line copies of the interim schedule on sheets of paper 765 x 1070 mm (30 x 42 inches) and an electronic file in the previously approved CPM schedule program. The submittal shall also include three copies of a computer-produced activity/event ID schedule showing project duration; phase completion d

16、ates; and other data, including event cost. Each activity/event on the computer-produced schedule shall contain as a minimum, but not limited to, activity/event ID, activity/event description, duration, budget amount, early start date, early finish date, late start date, late finish date and total f

17、loat. Work activity/event relationships shall be restricted to finish-to-start or start-to-start without lead or lag constraints. Activity/event date constraints, not required by the contract, will not be accepted unless Provided by IHSNot for ResaleNo reproduction or networking permitted without li

18、cense from IHS-,-,-04-10M 01 32 16.15 - 3 submitted to and approved by the Contracting Officer. The contractor shall make a separate written detailed request to the Contracting Officer identifying these date constraints and secure the Contracting Officers written approval before incorporating them i

19、nto the network diagram. The Contracting Officers separate approval of the Project Schedule shall not excuse the contractor of this requirement. Logic events (non-work) will be permitted where necessary to reflect proper logic among work events, but must have zero duration. The complete working sche

20、dule shall reflect the Contractors approach to scheduling the complete project. The final Project Schedule in its original form shall contain no contract changes or delays which may have been incurred during the final network diagram development period and shall reflect the entire contract duration

21、as defined in the bid documents. These changes/delays shall be entered at the first update after the final Project Schedule has been approved. The Contractor should provide their requests for time and supporting time extension analysis for contract time as a result of contract changes/delays, after

22、this update, and in accordance with Article, ADJUSTMENT OF CONTRACT COMPLETION. D. Within 30 calendar days after receipt of the complete project interim Project Schedule and the complete final Project Schedule, the Contracting Officer or his representative, will do one or both of the following: 1. N

23、otify the Contractor concerning his actions, opinions, and objections. 2. A meeting with the Contractor at or near the job site for joint review, correction or adjustment of the proposed plan will be scheduled if required. Within 14 calendar days after the joint review, the Contractor shall revise a

24、nd shall submit three blue line copies of the revised Project Schedule, three copies of the revised computer-produced activity/event ID schedule and a revised electronic file as specified by the Contracting Officer. The revised submission will be reviewed by the Contracting Officer and, if found to

25、be as previously agreed upon, will be approved. E. The approved baseline schedule and the computer-produced schedule(s) generated there from shall constitute the approved baseline schedule until subsequently revised in accordance with the requirements of this section. F. The Complete Project Schedul

26、e shall contain approximately _work activities/events. Provided by IHSNot for ResaleNo reproduction or networking permitted without license from IHS-,-,-04-10M 01 32 16.15 - 4 1.6 WORK ACTIVITY/EVENT COST DATA A. The Contractor shall cost load all work activities/events except procurement activities

27、. The cumulative amount of all cost loaded work activities/events (including alternates) shall equal the total contract price. Prorate overhead, profit and general conditions on all work activities/events for the entire project length. The contractor shall generate from this information cash flow cu

28、rves indicating graphically the total percentage of work activity/event dollar value scheduled to be in place on early finish, late finish. These cash flow curves will be used by the Contracting Officer to assist him in determining approval or disapproval of the cost loading. Negative work activity/

29、event cost data will not be acceptable, except on VA issued contract changes. B. The Contractor shall cost load work activities/events for guarantee period services, test, balance and adjust various systems in accordance with the provisions in Article, FAR 52.232 5 (PAYMENT UNDER FIXED-PRICE CONSTRU

30、CTION CONTRACTS) and VAAR 852.236 83 (PAYMENT UNDER FIXED-PRICE CONSTRUCTION CONTRACTS). C. In accordance with FAR 52.236 1 (PERFORMANCE OF WORK BY THE CONTRACTOR) and VAAR 852.236 72 (PERFORMANCE OF WORK BY THE CONTRACTOR), the Contractor shall submit, simultaneously with the cost per work activity

31、/event of the construction schedule required by this Section, a responsibility code for all activities/events of the project for which the Contractors forces will perform the work. D. The Contractor shall cost load work activities/events for all BID ITEMS including ASBESTOS ABATEMENT. The sum of eac

32、h BID ITEM work shall equal the value of the bid item in the Contractors bid. 1.7 PROJECT SCHEDULE REQUIREMENTS A. Show on the project schedule the sequence of work activities/events required for complete performance of all items of work. The Contractor Shall: 1. Show activities/events as: a. Contra

33、ctors time required for submittal of shop drawings, templates, fabrication, delivery and similar pre-construction work. b. Contracting Officers and Architect-Engineers review and approval of shop drawings, equipment schedules, samples, template, or similar items. c. Interruption of VA Facilities uti

34、lities, delivery of Government furnished equipment, and rough-in drawings, project phasing and any other specification requirements. Provided by IHSNot for ResaleNo reproduction or networking permitted without license from IHS-,-,-04-10M 01 32 16.15 - 5 d. Test, balance and adjust various systems an

35、d pieces of equipment, maintenance and operation manuals, instructions and preventive maintenance tasks. e. VA inspection and acceptance activity/event with a minimum duration of five work days at the end of each phase and immediately preceding any VA move activity/event required by the contract pha

36、sing for that phase. 2. Show not only the activities/events for actual construction work for each trade category of the project, but also trade relationships to indicate the movement of trades from one area, floor, or building, to another area, floor, or building, for at least five trades who are pe

37、rforming major work under this contract. 3. Break up the work into activities/events of a duration no longer than 20 work days each or one reporting period, except as to non-construction activities/events (i.e., procurement of materials, delivery of equipment, concrete and asphalt curing) and any ot

38、her activities/events for which the COTR may approve the showing of a longer duration. The duration for VA approval of any required submittal, shop drawing, or other submittals will not be less than 20 work days. 4. Describe work activities/events clearly, so the work is readily identifiable for ass

39、essment of completion. Activities/events labeled “start,“ “continue,“ or “completion,“ are not specific and will not be allowed. Lead and lag time activities will not be acceptable. 5. The schedule shall be generally numbered in such a way to reflect either discipline, phase or location of the work.

40、 B. The Contractor shall submit the following supporting data in addition to the project schedule: 1. The appropriate project calendar including working days and holidays. 2. The planned number of shifts per day. 3. The number of hours per shift. Failure of the Contractor to include this data shall

41、delay the review of the submittal until the Contracting Officer is in receipt of the missing data. C. To the extent that the Project Schedule or any revised Project Schedule shows anything not jointly agreed upon, it shall not be deemed to have been approved by the COTR. Failure to include any eleme

42、nt of work required for the performance of this contract shall not excuse the Contractor from completing all work required within any applicable completion date of each phase regardless of the COTRs approval of the Project Schedule. Provided by IHSNot for ResaleNo reproduction or networking permitte

43、d without license from IHS-,-,-04-10M 01 32 16.15 - 6 D. Compact Disk Requirements and CPM Activity/Event Record Specifications: Submit to the VA an electronic file(s) containing one file of the data required to produce a schedule, reflecting all the activities/events of the complete project schedul

44、e being submitted. 1.8 PAYMENT TO THE CONTRACTOR: A. Monthly, the contractor shall submit the AIA application and certificate for payment documents G702 and an electronic file (s) of the resulting monthly updated schedule. B. Approval of the Contractors monthly Application for Payment shall be conti

45、ngent, among other factors, on the submittal of a satisfactory monthly update of the project schedule. 1.9 PAYMENT AND PROGRESS REPORTING A. Monthly schedule update meetings will be held on dates mutually agreed to by the COTR and the Contractor. Contractor and their CPM consultant (if applicable) s

46、hall attend all monthly schedule update meetings. The Contractor shall accurately update the Project Schedule and all other data required and provide this information to the COTR three work days in advance of the schedule update meeting. Job progress will be reviewed to verify: 1. Actual start and/o

47、r finish dates for updated/completed activities/events. 2. Remaining duration for each activity/event started, or scheduled to start, but not completed. 3. Logic, time and cost data for change orders, and supplemental agreements that are to be incorporated into the Project Schedule. 4. Changes in ac

48、tivity/event sequence and/or duration which have been made, pursuant to the provisions of following Article, ADJUSTMENT OF CONTRACT COMPLETION. 5. Completion percentage for all completed and partially completed activities/events. 6. Logic and duration revisions required by this section of the specif

49、ications. Provided by IHSNot for ResaleNo reproduction or networking permitted without license from IHS-,-,-04-10M 01 32 16.15 - 7 7. Activity/event duration and percent complete shall be updated independently. B. After completion of the joint review, the contractor shall generate an updated computer-produced calendar-dated schedule and supply the Contracting Officers representative wi